WRITE ME UP A VERBAL CONTRACT
A miniature golf operation called Oasis Park hired Bill Oberholtzer – who was both a miniature golf course owner and a mini golf course builder – to jazz up Oasis Park before the mini golf season started up in the Troy, New York, area. Disregarding the universally-accepted good practice in construction of starting with a nice, neat signed agreement setting out the scope of the work, payment terms, time to completion and other such details, the Oasis Park people and Bill pretty much sketched out their agreement on the back of a cocktail napkin. And that was a mistake.
Later, Oasis Park needed a more formal document in order to get its bank to release financing. Bill, of course, accommodated Oasis Park by signing one. You can guess what happened. When the parties’ working relationship soured, Oasis claimed that the accommodation document – and not the “cocktail napkin” – was the real deal between the parties covering the scope of the work. Bill countered that he had already been working for weeks, and the plans had changed.
Nevertheless, within six weeks after some fateful April 29 “thing” occurred — and even the Court couldn’t tell what the “thing” was — Oasis fired Bill amid claims that he hadn’t adhered to some nonexistent schedule, hadn’t provided workers, and hadn’t provided materials. For good measure, Oasis claimed that Bill’s work was substandard.
Bill naturally argued just the opposite, asserting that he couldn’t buy supplies because Oasis Park wouldn’t pay him. The whole mess ended up in federal court, where the Judge threw up his hands and said no one was getting summary judgment. The entire kerfluffle was going have to be sorted out at trial.
So now, let’s all grab our calculators and figure out how Bill saved by not wasting money on a lawyer preparing a contract with Oasis Park up front. Not much, we guess. And you arborists, tree trimmers, loggers and owners – let’s remember this: No contract, no winners.
Paone, Inc. v. Oberholtzer, Slip Copy, 2007 WL 2455074 (N.D.N.Y., Aug. 23, 2007). Oberholtzer agreed to provide all labor and materials necessary to remodel Paone’s miniature golf course. Beyond that fact, the parties could agree on nothing.
Paone said that under a contract dated April 29, 2004, Oberholtzer to build a bumper boat pond, including walls, docks, light fixtures, a cave, a filter system, a perimeter walkway, and a staging-area deck. As well, Paone said, the contract required Oberholtzer to renovate the course’s clubhouse entrance, the third hole, and the practice green. Paone said that under to the contract, Oberholtzer began working in May 2004, but its laborers did not show up for work, causing the project to fall behind schedule. To rectify the situation, Paone claims that it hired temporary workers.
Even with these outside laborers, the project did not move forward because Oberholtzer failed to provide supervision and direction. Paone said it had to supply all materials to the site and hire various construction professionals to inspect the work. Paone contended that these professionals found that Oberholtzer’s work violated building-code requirements and was below the industry standard. After the project had gone on about a month, Paone notified Oberholtzer that it was in default of the contract.
Oberholtzer, on the other hand, claimed that he reached an agreement to perform work for Paone well prior to April 29, 2004. Oberholtzer said he began preparatory work in March. The April 29th document, Oberholtzer contended, was merely an estimate prepared at Paone’s request,intended by both parties to help Paone get a bank loan released. The April 29, 2004, agreement was conformed to an earlier budget from the winter of 2003-2004, which Paone had submitted to the bank to support its initial loan application.
Consequently, Oberholtzer argued, the estimate did not reflect intervening changes of which both parties were aware, including a different location for the bumper boat pond, changes in site elevations for the clubhouse and parking lot which required alteration of a ramp and deck, and additional concrete walkways on the course.
Oberholtzer said, he had already made significant progress before April 29, 2004, including filling in traps, reconfiguring the practice green, removing an existing sidewalk near the old practice green, building a deck between the seventh and eighth holes, and removing fixtures and equipment from the old clubhouse. What’s more, Oberholtzer asserted, he had also cleared and trimmed trees for a new picnic area, built retaining walls for a walkout basement, constructed a deck attached to the clubhouse, erected bumper boat pond walls and skimmer baskets, and backfilled the pond.
As far as the schedule went, Oberholtzer argued that the April 29, 2004, document did not contain a schedule or other time-related requirements. Oberholtzer said that Paone knew Oberholtzer would be opening and operating his own miniature golf course in Georgia at the end of May. Therefore, Oberholtzer claimed, Paone knew that Oberholtzer would not be available to work on the project on a regular basis. Furthermore, Oberholtzer argued that several weeks of delay resulted from the actions of an unrelated contractor, who placed heavy equipment in the area of the future bumper boat pond. Also, he said, Paone failed to make timely payments to enable Oberholtzer to buy materials and to progress with the project. Finally, Oberholtzer complained that Paone approved all building plans, and that town building inspectors routinely inspected the progress and noted no building code violations.
Paone sued for breach of the contract and for negligence, and then moved for summary judgment.
Held: Summary judgment was denied in this fact-laden morass. The Court observed that Paone’s causes of action for breach of contract and breach of the implied covenants of good faith and fair dealing both required first that there be an enforceable contract with sufficiently definite terms. Here, the parties could not even agree on whether the document was a contract, let alone what its terms might be. Paone contended the document represents the parties’ complete agreement, but Oberholtzer asserted that the document was an estimate used solely for the purpose of obtaining funding. While Paone said that the time for performance commenced in May 2004, Oberholtzer alleged that it had already completed substantial portions of the project prior to that time.
What’s more, the Court found, reference to the April 29, 2004, document wasn’t helpful because it contained no details about the parties’ responsibilities or the construction schedule. The document was labeled “Spring 2004 Construction” and merely set forth the various projects and the price for each. In light of these disputes, the Court held, it could not determine whether an enforceable contract existed between the parties without evaluating the parties’ conflicting factual accounts. Moreover, on the basis of the April 29, 2004 document alone, the Court could not determine the construction schedule or the parties’ respective contractual responsibilities.
A trial would be necessary to straighten the whole mess out.
– Tom Root